These Terms and Conditions (“Terms”) govern your use of https://nfhomeimprovement.com/ (the “Site”) and the services provided by NF Home Improvements, located in West Park, FL (“we,” “us,” or “our”). By accessing or using this Site, you agree to be bound by these Terms and any future updates or changes. If you do not agree to these Terms, please do not use the Site.
1. Acceptance of Terms
By visiting our Site or using any of our services, you agree to comply with and be bound by these Terms and Conditions, as well as our Privacy Policy.
2. Services
NF Home Improvements provides home remodeling services, including but not limited to kitchen and bathroom remodeling, home additions, and other renovation projects. All services are subject to availability, and we reserve the right to modify or discontinue services at any time without prior notice.
3. User Responsibilities
You agree to use the Site only for lawful purposes and in accordance with these Terms. You must not:
- Violate any applicable laws or regulations.
- Attempt to gain unauthorized access to our systems or interfere with the operation of the Site.
- Use the Site to transmit any harmful or illegal content, including malware or viruses.
4. Project Proposals & Acceptance
Each project begins with a written proposal that outlines the scope, schedule, payment terms, and deliverables. Your written acceptance of the proposal or down payment confirms your agreement to the outlined terms.
5. Payment Terms
- Deposit: A non-refundable deposit is required to confirm the project, typically 10-30% of the total project cost.
- Progress Payments: Scheduled based on project milestones. These payments must be made on time.
- Final Payment: Due upon project completion, prior to final inspection or handover.
- Late Payments: Any overdue payments may incur interest at a rate of 1.5% per month or the maximum allowed by law.
6. Changes to the Scope of Work
Any changes to the original scope of work must be documented in writing. These changes may result in adjustments to the project cost and timeline. Work will not proceed until a signed change order is received and any applicable additional payments are made.
7. Timeline & Delays
While we strive to complete all projects according to the agreed-upon timeline, delays may occur due to unforeseen circumstances, including weather conditions, supply chain issues, or other external factors. We will notify you promptly of any delays and work with you to adjust schedules.
8. Warranty
Our services are backed by a warranty covering defects in workmanship for a specified period. Materials and products may also have their own manufacturer warranties, and we will provide details where applicable. This warranty does not cover damages caused by misuse, neglect, or external factors beyond our control.
9. Limitation of Liability
To the maximum extent permitted by law, NF Home Improvements shall not be liable for any indirect, incidental, or consequential damages arising from your use of the Site or our services. Our total liability shall not exceed the amount paid for the services in question.
10. Intellectual Property
All content, designs, logos, images, and other materials on the Site are the property of NF Home Improvements and are protected by copyright and intellectual property laws. You may not use, reproduce, or distribute any materials from the Site without our prior written consent.
11. Indemnification
You agree to indemnify and hold NF Home Improvements, its employees, contractors, and affiliates harmless from any claims, damages, or expenses arising from your use of the Site or violation of these Terms.
12. Governing Law
These Terms shall be governed by and construed in accordance with the laws of the State of Florida, without regard to its conflict of law principles. Any disputes related to these Terms shall be resolved in the courts located in Broward County, Florida.
13. Changes to Terms
We reserve the right to update or modify these Terms at any time. Any changes will be posted on this page, and the “Effective Date” will be updated accordingly. Please review these Terms regularly to stay informed of any updates.
14. Contact Us
If you have any questions or concerns about these Terms, please contact us at:
NF Home Improvements
954-761-576
info@nfhomeimprovement.com